What is FAR 52.211-12?

FAR 52.211-12 (Liquidated Damages—Construction.) is a federal acquisition regulation clause that may be included in government contracts. It falls under the general category.

When is FAR 52.211-12 required?

FAR 52.211-12 is typically required when the contracting officer determines it's applicable to the specific procurement. Check the solicitation's Section I for included clauses.

Does FAR 52.211-12 flow down to subcontractors?

Whether FAR 52.211-12 flows down depends on the specific clause language and contract type. Review the clause text for flow-down provisions.

Low RiskFARGeneral

52.211-12 — Liquidated Damages—Construction.

Last updated: 2026-04

Researched by the BidStride Research Team

What This Clause Requires

FAR 52.211-12 — Liquidated Damages—Construction.. This clause is part of the Federal Acquisition Regulation and may be included in government contracts as a solicitation provision or contract clause.

Official Regulation Text

52.211-12 Liquidated Damages—Construction. As prescribed in 11.503(b), insert the following clause in solicitations and contracts: Liquidated Damages—Construction (SEP 2000) (a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of __ [ Contracting Officer insert amount ] for each calendar day of delay until the work is completed or accepted. (b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (End of clause) [65 FR 46067, July 26, 2000]
Source: eCFR, 48 CFR 52.211-12 (https://www.ecfr.gov/current/title-48/section-52.211-12)

Compliance Checklist

As prescribed in 11.503(b), insert the following clause in solicitations and contracts: Liquidated Damages—Construction (SEP 2000) (a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of __ [ Contracting Officer insert amount ] for each calendar day of delay until the work is completed or accepted.

Flow-Down to Subcontractors

No flow-down required

This clause applies only to the prime contract and does not need to be flowed down to subcontractors.

Frequently Asked Questions

BidStride automatically scans your RFPs for 52.211-12

Stop hunting through solicitations manually. BidStride identifies every FAR and DFARS clause in your RFP, flags risk level, and surfaces compliance requirements before you submit your bid.

This summary is for informational purposes only and reflects the BidStride Research Team's plain-English interpretation of the regulation. It is not legal advice and does not constitute an attorney-client relationship. Always consult the official Federal Acquisition Regulation (FAR) or Defense Federal Acquisition Regulation Supplement (DFARS) text and qualified legal counsel for compliance decisions.