What is FAR 52.211-13?

FAR 52.211-13 (Time Extensions.) is a federal acquisition regulation clause that may be included in government contracts. It falls under the general category.

When is FAR 52.211-13 required?

FAR 52.211-13 is typically required when the contracting officer determines it's applicable to the specific procurement. Check the solicitation's Section I for included clauses.

Does FAR 52.211-13 flow down to subcontractors?

Whether FAR 52.211-13 flows down depends on the specific clause language and contract type. Review the clause text for flow-down provisions.

Low RiskFARGeneral

52.211-13 — Time Extensions.

Last updated: 2026-04

Researched by the BidStride Research Team

What This Clause Requires

FAR 52.211-13 — Time Extensions.. This clause is part of the Federal Acquisition Regulation and may be included in government contracts as a solicitation provision or contract clause.

Official Regulation Text

52.211-13 Time Extensions. As prescribed in 11.503(c), insert the following clause: Time Extensions (SEP 2000) Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule. (End of clause) [65 FR 46067, July 26, 2000]
Source: eCFR, 48 CFR 52.211-13 (https://www.ecfr.gov/current/title-48/section-52.211-13)

Compliance Checklist

Flow-Down to Subcontractors

No flow-down required

This clause applies only to the prime contract and does not need to be flowed down to subcontractors.

Frequently Asked Questions

BidStride automatically scans your RFPs for 52.211-13

Stop hunting through solicitations manually. BidStride identifies every FAR and DFARS clause in your RFP, flags risk level, and surfaces compliance requirements before you submit your bid.

This summary is for informational purposes only and reflects the BidStride Research Team's plain-English interpretation of the regulation. It is not legal advice and does not constitute an attorney-client relationship. Always consult the official Federal Acquisition Regulation (FAR) or Defense Federal Acquisition Regulation Supplement (DFARS) text and qualified legal counsel for compliance decisions.