52.236-11 — Use and Possession Prior to Completion.

FAR 52.236-11 — Use and Possession Prior to Completion.. This clause is part of the Federal Acquisition Regulation and may be included in government contracts as a solicitation provision or contract clause.

52.236-11 Use and Possession Prior to Completion. As prescribed in 36.511, insert the following clause: Use and Possession Prior to Completion (APR 1984) (a) The Government shall have the right to take possession of or use any completed or partially completed part of the work. Before taking possession of or using any work, the Contracting Officer shall furnish the Contractor a list of items of work remaining to be performed or corrected on those portions of the work that the Government intends to take possession of or use. However, failure of the Contracting Officer to list any item of work shall not relieve the Contractor of responsibility for complying with the terms of the contract. The Government's possession or use shall not be deemed an acceptance of any work under the contract. (b) While the Government has such possession or use, the Contractor shall be relieved of the responsibility for the loss of or damage to the work resulting from the Government's possession or use, notwithstanding the terms of the clause in this contract entitled Permits and Responsibilities. If prior possession or use by the Government delays the progress of the work or causes additional expense to the Contractor, an equitable adjustment shall be made in the contract price or the time of completion, and the contract shall be modified in writing accordingly. (End of clause) [48 FR 42478, Sept. 19, 1983, as amended at 60 FR 34761, July 3, 1995]

• As prescribed in 36.511, insert the following clause: Use and Possession Prior to Completion (APR 1984) (a) The Government shall have the right to take possession of or use any completed or partially completed part of the work.
• Before taking possession of or using any work, the Contracting Officer shall furnish the Contractor a list of items of work remaining to be performed or corrected on those portions of the work that the Government intends to take possession of or use.
• However, failure of the Contracting Officer to list any item of work shall not relieve the Contractor of responsibility for complying with the terms of the contract.
• The Government's possession or use shall not be deemed an acceptance of any work under the contract.
• (b) While the Government has such possession or use, the Contractor shall be relieved of the responsibility for the loss of or damage to the work resulting from the Government's possession or use, notwithstanding the terms of the clause in this contract entitled Permits and Responsibilities.
• If prior possession or use by the Government delays the progress of the work or causes additional expense to the Contractor, an equitable adjustment shall be made in the contract price or the time of completion, and the contract shall be modified in writing accordingly.